Description As per document Pre-Qualification: pls visit unionbankofindia.com/tenderinfo.aspx UNION BANK OF INDIA Regional Office (N) Dhanlaxmi Industrial Estate Thane (west) Telephone: 21721144 ----------------------------------------------------------------------------------------------------------------- SUBJECT Electrical Work at Sanpada Branch _________________ _____________________________________________________________ ISSUE OF TENDERS FROM 10.04.2010 TO 30.04.2010 LAST DATE OF SUBMISSION 30.04.2010 UPTO 3.00 pm HOURS. TENDER OPENING DATE 30.04.2010 TIME 4.00pm (TENDERS WILL BE OPENED IN PRESENCE OF CONTRACTING AGENCIES) PLACE OF SUBMISSION: UNION BANK OF INDIA Regional Office (north) First Floor, Dhanlaxmi Industrial Estate Opp. Gokul Nagar, Thane (west) Pin 400601 TENDER ISSUED TO: M/S______-____________________________________________________ 2 TENDER NOTICE Subject: Electrical Work at Sanpada Branch 1. Sealed item rate tenders are invited by M/s Union Bank of India, Regional Office (north),Thane, first floor, Dhanlaxmi Industrial Estate, Gokul Nagar Thane_(west) from approved contractors on bank’s panel in Mumbai and Thane Region, for Electrical Work. The approximate cost of the work is Rs.3.76 lacs 2. The work to be completed within 30 days from 3rdday of the date of acceptance of work order placed by M/s Union Bank of India. 3. The tenderers are required to complete form of tender, price the schedule of quantities and sign each page of tender documents before submission. The completed set is to be enclosed in a sealed envelope addressed to : Dy. General Manager Regional Office (North) Dhanlaxmi Industrial Estate First Floor,opp.Gokul Nagar Thane (West) Pin 400601 4. Tenders will be received upto 3.00pm hours on 30.04.2010. 5. No tender will be received after the expiry of the time notified for receiving tenders under any circumstances whatsoever. 6. The tender will be opened at 4.00pm hours on 30.04.10 at above address in the presence of authorized representative of contracting agency. 7. Tender shall remain valid for acceptance for a period of 90 days from the notified last date of tender submission. 8. The Bank reserve the right to reject any or all tenders received without assignment of any reasons thereof. 9. The tender rate against each item of work / price indicated in the schedule of quantities and rates / price should be indicated both in words and figures. In case of any discrepancy, the rates indicated in words would prevail. 10. The rates quoted against each item of work / price should be for the complete finished item of work and include all labour, material, taxes, overhead, duties, etc. Any statutory change in the tax structure after opening of the tender shall be reimbursed by the Bank as per actual. 11. Each tender shall be accompanied by Earnest Money of Rs.3760/-(Rs. Three thousand Seven Hundred Thirty Only) in the form of Pay Order / Demand Draft in favour of Union Bank of India, payable at Mumbai. Tenders without Earnest Money shall be summarily rejected. 12. The earnest money deposited shall not carry any interest and will be refunded to the unsuccessful tenderers. Earnest money paid by the successful contractor will be retained by the Bank till completion of the work. 13. Earnest money paid by contractor shall be forfeited by the Bank if contractor fails to undertake the job if he is communicated about acceptance of his rates. D:\D-Packages\Intranet-Correspondence\thane\sanpada\TENDER-Electrical.doc 3 14. All tenders in which any of the prescribed conditions are not fulfilled or incomplete in any respect are liable to be rejected. 15. This tender notice shall form part of the contract documents. For Union Bank Of India D:\D-Packages\Intranet-Correspondence\thane\sanpada\TENDER-Electrical.doc 4 GENERAL CONDITIONS OF CONTRACT Subject : Electrical Work at Sanpada Branch General Instructions to Contractor 1 Inspection of sites: The contractor shall visit and examine the site and satisfy as to the nature and correct dimensions of work and facilities for obtaining material and shall obtain generally his own information on all matters affecting the execution of work. No extra charge made in consequence of any misunderstanding or incorrect information on any of these points on the ground of insufficient description will be allowed. All expenses incurred by the contractors in connection with obtaining information for submitting this tender including his visit to site and efforts in compiling the tender shall be borne by the tenderer ad no claims for reimbursement thereof shall be entertained. 2 Safety Regulations: The contractor shall take all the necessary precautions while working and to safeguard adjacent property, Bank’s property, Bank’s employees, and traffic persons 3 Compliance to local laws: The contractor shall conform to the provisions of any Act of the Legislature relating to the work and to the Regulation of Bye Laws of any authority. He shall also obtain the permission of the Municipality or any other Authorities if required under the existing rules. 4 Site cleaning: All the rates quoted are inclusive of removal of rubbish / debris collected during the progress of work, rejected material and clearance of site before and after the work is completed. Not more than one truck load shall be stored that to for not more than 3 days. The contractor shall arrange to remove the same immediately. If the contractor is failing to remove the same and the expenses shall be recovered from the contractor and he will not dispute for the expenses so incurred. 5 Vouchers / bills: Contractor shall upon the request of the Bank furnish bills, invoices, accounts, receipts and other vouchers for all materials brought on site to prove that the material purchased are as mentioned in the specification. 6 Contractor’s responsibility: The work will from time to time be examined, but such examination shall not in any way exonerate the contractor from the obligation to remedying any defects which may be observed at any stage of the work or after the same is completed. 7 Dismissal from work: The contractor shall upon the written request of the Bank’s Architect / Engineer immediately dismiss from the work any person employed by him thereon, who may in the opinion of the authority be incompetent or misconduct himself and such person shall not be again employed on the work, without the permission of the bank. 8 Order of work, etc.: Bank reserves the right to fix the order in which the various items of work involved are to be executed. However, the contractor shall be responsible for the completion of the entire job within the item limit specified failing which liquidated damages as mentioned in clause No.49 shall be recovered from the contractor. 9 Commencement of work: The work must be started within 3 days upon accepting the work order and the programme for carrying out the various jobs shall be drawn out. D:\D-Packages\Intranet-Correspondence\thane\sanpada\TENDER-Electrical.doc 5 Adequate labour force shall be provided to complete the work within the specified period. Proper security aspects should be taken care of by adequate vigilance in view of the importance of the building. Default in compliance with the programmes so finalised shall entail operation of liquidated damages as stated. 10 Subletting the work: The contractor shall not directly or indirectly sublet the work to other party without written permission from the bank. 11 Quantities of works are provisional: The quantities mentioned in schedule are provisional and likely to increase / decrease to any extent or may be omitted thus altering the aggregate value of the contract. No claim for loss of profit / business shall be entertained on this account 12 Distribution of work: The Bank reserve the right to distribute the work for which quotation have been called, among more than one parties, if found necessary. No claim in this respect shall be considered and the contractor agrees to cooperate with other agencies appointed by the bank. 13 Third party damage: The contractor shall be responsible for all injury to persons, animals, building, building structure, any damage to road, streets, footpaths and shall rectify it at its own cost. 14 Insurance cover: All the workers of the contractor as well as his sub-contractor must be properly covered by an Insurance Policy under Workman’s Compensation Act and Fatal Accidents Act. The contractor at his own expenses arrange to effect and maintain until the virtual completion of the contract, insurance policy in the joint name of the Bank and the contractor against this risk to be retained by the Bank until the virtual completion of the work, and indemnify the Bank from all the liabilities arising out of such events. In case of delay, contractor shall arrange to extend insurance policy till work is completed. 15 Delay & Extension of time: All the work should be completed within the specified period in the tender. If the work is delayed due to the reasons beyond the control of the contractor, he should applying to the Bank explaining, therein the reasons for such delays, immediately and if in the opinion of Bank’s authorities the delay is justified, the contractor shall be granted extension in time limit. 16 Certificate of virtual completion: As soon as the work is completed, the contractor shall inform in writing such completion to the Bank’s Architect / Engineer who will inspect the work and if satisfied will issue the certificate that the work has been virtually completed and the defects liability period shall commence from the date of such certificate. 17 Defect liability period: The defects or other faults which may appear during the defect liability period which is 12 months after the virtual completion of the work, arising in the opinion of the bank due to inferior quality of material or bad workmanship not in accordance with the contract, contractor shall make good at his own cost within a reasonable time. In case of default, Bank may employ and pay other agencies to amend and make good such defects and all expenses / damages / losses shall be recoverable by Bank or may be deducted from any money due to the contractor 18 Arrangement of work: The contractor shall organise the work in such a way that the office users or the nearby public area put to no hardships and the working of the office is not affected. The contractor shall take adequate care during the progress of work to protect the office property like stationery, furniture, etc. In case of any damage, the same shall be made good by the contractor. Contractor is agreed to work after office hours for which no extra cost shall be considered. D:\D-Packages\Intranet-Correspondence\thane\sanpada\TENDER-Electrical.doc 6 19 Stacking of material: The contractor is not to stack any of his material recklessly so as to endanger the safety of the building and cause any nuisance to the occupants and the public. 20 Extra charges: It must be clearly understood that all the conditions of contracts are intended to be strictly enforced and that no extra charges in respect of extra work will be allowed unless they are clearly outside the spirit and meaning of the condition and unless such work shall have been ordered in writing. 21 Protection of material and work: The contractor shall be responsible for storing and watching his own material and protecting the work at his own cost. The contractor and his worker will be allowed to use lift after office hours. However, no paint drums or heavy bag of cement / paint will be allowed to be taken into the lift. Any damage / spoiling of lift / floor / dado caused during such act will have to be made good by the contractor at his own expenditure. 22 Water supply: The contractor shall make his own arrangement for water required for the work. in case the water is available and supplied by the Bank, the charges for the same shall be recovered at the rate of 1% of value of the work executed. In case water supplied by the Bank, the contractor shall make his own arrangement for the storage, pipeline from point of tape of to the required location. 23 Electric supply: Electricity will be supplied by the Bank, the contractor shall make his own arrangement for providing points, wires lines, extension board wherever it is required in the premises, in and out. 24 Approval of samples: The contractor shall furnish well in time before work commence at his own cost, colour samples, samples of material or workmanship that may be called by Bank’s Architect / Engineer for approval. Rates quoted shall cover for such preliminary work. 25 Workmanship: The work involved calls for a high standard of workmanship combined with speed. All the glass panes, door handles / hinges, electric fitting, fans, furniture records, floors etc. are to be thoroughly cleaned after work is completed. Any damage to the flooring, tiles, dado, panelling or any other part of the building, etc. shall be made good at the cost of the contractor to the entire satisfaction of the Bank. Contractor shall make all arrangements for shifting of furniture / records and keeping the same in its original position after he finishes the work on daily basis. The contractor at his own cost shall provide brown paper, polythene, tarpaulin etc. for protecting furniture / fixtures, paneling, electrical, fittings, records, etc. 26 Interpretation of documents / drawing: Except where otherwise provided in the contract all questions and disputes relating to the meaning of the specifications, design drawings and instructions herein before mentioned and as to the quality of workmanship or materials used for the work or as to any other question, claim, right, matter or thing whatsoever, in any way arising out of or relating to the contract, designs, drawings specifications, estimates, instructions, orders or these conditions or otherwise concerning the works, or the execution or failure to execute the same whether arising during the progress of the work or after the completion or abandonment thereof shall be referred to the competent authority of the Bank whose decision shall be final and binding on the contractor. 27 Use of scaffolding: The contractor shall allow the use of scaffolding erected by them to any other agency employed by the Bank during the contract period without any payment. 28 Provisional Item: If ordered by the Bank, contractor shall be required to carry out provisional items at the same conditions and rates as applicable for this contract. D:\D-Packages\Intranet-Correspondence\thane\sanpada\TENDER-Electrical.doc 7 29 Measurements of all concealed items: Measurements of all concealed items of work and extra item if any, shall be got recorded by the Bank’s Architect / Engineer before they are checked up. 30 Measurements: All measurement tapes shall be of steel and all scaffolding and ladders that may be required for taking measurements shall be supplied by the contractor. 31 Cleaning during the work: The rates quoted shall include cleaning of ceiling roses, electric switches, boards, window panes etc. after the repairing leaving the site neat and tidy from time to time. 32 Complying I.S. specification: Unless otherwise mentioned in the contract, the latest Indian Standard Code for material specifications, method of work, mode of measurements shall be followed. The payment shall be made on the basis of actual measurement of work done to be submitted along with bill 33 Rate to include: The rates quoted by the contractor shall cover for work at any height in the premises for all finished items under this contract. The rate quoted shall be inclusive of all material cost, wastage, labour, loading, profit, taxes if any, scaffolding, transport, supervision, spot light arrangement and any other means to complete the job. Octroi, sales-tax, works contract tax or any other taxes present or future to be included in the rates so quoted. If there is a change in the tax structure / duties as per State / Central Govt. order after opening of tender, the Bank shall reimburse difference in tax as per actual. 34 Price Fluctuation: The rates quoted by the contractor shall be firm throughout the currency of contract (including extension of time if any granted) and will not be subject to any fluctuation due to variation in the cost of material or labour. 35 The successful tenderer if called upon to do so, shall obtain a letter from the approved trade manufacturer whose product is used, if found necessary by the Bank confirming that the manufacturer shall provide all the technical assistance and supervision during the execution of the work at all such places as directed and the contractor shall bear the expenses, if any, for such supervision and technical assistance supplied by the trade manufacturer. 36 Testing of materials: If at any point of time during the work, if Bank authorities desire to carry out the tests of certain materials, the contractor shall arrange for the same and submit the test report without any extra cost to the Bank. 37 The contractor shall note that they should bring to the notice of the Architect / Engineer any breakage in glass window before starting work. However, if any glass window is found to be broken during the repairing work, the same shall be replaced by the contractor at his own cost. 38 Conditional tenders: Conditional tenders are liable to be rejected. 39 Rates of non-tendered items: The successful tenderer is bound to carry out any item of work necessary for the completion of the job even though such items are not included in schedule of quantities. 40 Abandonment of work: If in any case the work required to be abandoned, the contractor shall not be entitled for any claims and he will be paid as per the actual work done till that period. 41 The Bank reserves the right to accept / reject the lower or any or all tenders in part or in whole without assigning a reason therefor. D:\D-Packages\Intranet-Correspondence\thane\sanpada\TENDER-Electrical.doc 8 42 Decision of the Bank shall be final and binding on any matter connected with the work. The matter of any dispute shall be decided after mutual discussions based on the terms and conditions of this contract. However, if the matter can not be resolved then the same shall be referred to the respected, qualified person in the field agreed to both the parties and his opinion shall be binding on both the parties. However, this is precourse to any legal action in this regard. 43 Incomplete quotation: Incomplete quotations shall be summarily rejected 44 Payments: The contractor shall be paid by the Bank from time to time under interim payment on account of works executed and when the value of work equal to the approximate value named in the Appendix as ‘Value of work for Interim Certificate’ has been executed in accordance with this contract. 45 When the work has been virtually completed and Bank’s Architects / Engineer has certified in writing that the work has been completed on the basis of detailed measurements and has made a final scrutiny and that there is no dispute items, rates, ad quantities, the contractor shall be entitled to the payment of the final bill in accordance with the final certificate which will be honored within the period specified in the Appendix as period of honouring final certificate. 46 The contractor shall be paid by the Bank within the period named in Appendix (period of honouring certificate) after such certificate has been delivered to the employer by the Bank’s Architect / Engineer. Bank’s Architect / Engineer has power to withhold any certificate in the work or any part thereof are not carried out to his satisfaction or the contractor fails to show the desired progress or fails to follow the instructions given or in case of breach of this contract. 47 For water proofing works on traces, bathroom, WC, Chajja, work has to be executed through the agency specialized in waterproofing. Contractor will have to submit a guarantee of 10 years on stamp papers as per the format toe be prescribed by the Bank. 48 Earnest Money Deposit of successful tenderer shall be treated as security deposit. The contractor should pay this amount to the Bank by DD or PO at the time of submission of tender. This amount shall be retained by the Bank till the work is virtually completed and all amounts relating thereto settled. Second part of security deposit shall be built through the retentions from interim and final bills of the contractor and the amount of retention shall be as stated in the Appendix. 49 When the certificate of the virtual completion is issued to the contractor the security deposit in the form of EMD and 50% of retention money shall be refunded, provided that the contractor has fulfilled all the conditions of contract and further provided that the employer has no claim for forfeiture of part or whole of the said deposit. The balance 50% of the retention money built up through retention from interim and final bills will be returned to the contractor after the expiry of defect liability period, subject to deductions for any appropriations thereof required to be made by the Bank as per conditions of the contract. The contractor should note that no interest will be allowed on his security deposit. 50 The contractor is requested to sign each page of the quotation and put rubber stamp, seal below his signature and seal the quotation in an envelope. 51 Liquidated damages: If the contractor fails to maintain the required progress or to complete the work and clear the site or before the contract or extended date period of completion, he shall without prejudice to any other right , pay as agreed compensation amount of 1% of contract amount per week of delay subject to maximum of 10% of contract amount as liquidated damages. D:\D-Packages\Intranet-Correspondence\thane\sanpada\TENDER-Electrical.doc 9 52 Records & measurements: Measurements shall be taken jointly by Bank’s Architect / Engineer and contractor and shall without extra charges provide assistance with appliance, labour and other things necessary for the work and measurements will be signed and dated by both the parties on completion of measurements. 53 Safety measures: The contractor at his own cost shall provide tarpaulins on the external side of the building at the time of breaking plaster etc. to safeguard adjacent property, Bank’s property, employees, traffic, etc. The contractor shall follow all the safety measures while carrying out the work. Employer that is Bank shall not be liable for any compensation due to accident, any mishap or negligence. 54 If there is delay in commencement of work for any reason, the employer that is Bank shall not be liable for any compensation. 55 If at any point of time during the progress, it is observed that the contractor is not progressing the work with due diligence, care and lagging much behind the schedule or fails to gear up the work despite instructions from Bank’s Architects, the employer (Bank) reserves the right to terminate the contract with 7 days notice. In such case, the contractor shall be liable to pay the employer any extra cost involved for the completion of the said work and will not obstruct any way in completing the work through other agency. After completion of entire work the contractor shall be paid for the actual work executed by him at the quoted rates after deducting any claims, damages. In case of such termination the security deposit held by the Bank will be forfeited 56 Although the number of coats of paints / polishing / white washing are specified the contractor will have to additional coats if the surface is not to the satisfaction of the Bank’s Architect / Engineer and there shall be no extra payment on account of such coats 57 First Aid: The contractor shall be responsible for all first aid and he shall keep the site fully equipped to meet such emergency. 58 Supervision: The contractor is required to have on site during all working hours a competent supervisor (acceptable to Bank) who will be responsible for the conduct of worker and who has authority to receive and act on such instructions issued by the Architect / Engineer of Bank. 59 All work shall be carried out in a workman-like manner to the entire satisfaction of the Architect / Engineers. 60 Contractor shall follow all rules / regulations in force and should possess the license for employing labour and also follow all safety measures, labour bye law and shall be responsible for any lapse. 61 Transfer of Tender Documents: Transfer of tender documents purchased by one intending tenderer to another is not permissible. 62 Safety: The contractor shall carry out the entire work in a workman like manner having full regard for the safety of the men working at site. All safe practices shall be strictly adhered to by the workmen of the contractor like wearing helmets, safety belts when working at heights, gloves when handling sharp objects and reinforcement, eye shields during welding, safety shoes, etc. The contractor shall protect sides of openings in floor slabs, edges of slabs, stairs, stairwells etc. with barricades, warning signs / lights and educate all his workmen regarding following safe working practices. He shall provide first aid boxes at site. In spite of following safe methods, in case of any unfortunate accident, the contractor shall indemnify the employer against any expenses or claims towards treatment or compensation. D:\D-Packages\Intranet-Correspondence\thane\sanpada\TENDER-Electrical.doc 10 63 A Daily Diary Register: A daily diary register (with cement and steel stock statement) will be kept in the Engineer’s Office or the site office. The contractor or his representative will furnish every day at 9.00 hrs. details of work for the day proceeding and the diary will be written up every day and jointly signed by the Engineer and the Contractor or their representatives in token of its correctness. 64 Nuisance: The contractor shall not any time do cause or permit anyone to do or cause any nuisance on the site or do anything which shall cause unnecessary disturbance of inconvenience to the Employer or to the owners, tenants or occupiers of other properties near the site and to the public generally. 65 Rights, remedies and powers: I) Termination of contract due to contractor’s default. If the contractor: a. Abandon the contract. b. At any time defaults in proceedings with the works with due diligence and continues to do so after a notice in writing of seven days from the Engineer or Project Architect or Employer, or c. Commits default in complying with any of the terms and conditions of the contract and does not remedy it within 7 days after a notice in writing is given to him in that behalf of the Engineer or Project Architect or Employer. d. Persistently disregards the instructions of the Engineer, Project Architect or contravenes any provision of the contract, or e. Fails to remove materials from the site or to pull down and replace work after receiving from the Engineer, Project Architect notice to the effect that the said materials or works have been rejected. f. Fails to complete the works or items of work on or before the stipulated date (s) of completion, and does not complete them within the period specified in a notice given in writing in that behalf by the Engineer, or Project Architect of Employer, or g. Offer or gives or agrees to give to any person in the Employer’s service or to any other person on this behalf, any gift or consideration of any kind as an inducement or reward for doing or forbearing to do so for having done or forborne to do any act in relation to the obtaining or execution of this or any other contract for the Employer, or h. Shall enter into a contract with the Employer in connection with which commission has been paid or agreed to be paid by him or to his knowledge, unless the particulars of any such commission and the terms of payment thereof have previously been disclosed in writing to the Employer / Engineer, or i. Shall obtain a contract with the Employer as a result of ring tendering or other non-bonafide methods of competitive tendency, or j. Being an individual, or if a firm, any partner thereof, shall at any time be adjudged insolvent or have a receiving order or order for administration of his estate made against him or shall take any proceedings for liquidation or composition (other than a voluntary liquidation fir the purpose of amalgamation or reconstruction) under any Insolvency Act for the time being in force or make any conveyance or assignment of his effects or composition or arrangement for the benefit of his creditors or support so to do, or any application be made under any Insolvency Act for the time being in force for the sequestration of his estates or if a trust deed be executed by him for D:\D-Packages\Intranet-Correspondence\thane\sanpada\TENDER-Electrical.doc 11 benefit of his creditors, or k. Being a company, shall pass a resolution or the court shall make an order for the liquidation of its affairs, or a appointed or circumstances shall arise which entitle the court or debenture holders to appoint a receiver or manager, or l. Shall suffer an execution being levied on his goods and allow it to be continued for a period of 21 days, or m. Assigns, transfers, sublets (engagement of labour on a piece work basis or of labour with materials not to be incorporated in the work, shall not be deemed to be sub-letting) or attempts to assign, transfer or sub-let the entire works, or any portion thereof without the prior written approval of the employer. The Bank may, without prejudice to any other right or remedy which shall have accrued or shall accrue thereafter as the Employer by written notice determine the contract either as a whole or in part. II) Upon such determination of the contract in whole or in part, the security deposit with the Employer in respect of the contract shall stand forfeited to the Employer without in any way effecting the rights of the Employer. III) Rights of the employer after determination of the contract due to contractor’s default. The Engineer shall on such determination have powers to: a. Take possession of the site and any materials equipment, plant, implements stores etc. thereon, and / or b. Carry out the incomplete work by any means at the risk and cost of the contractor. IV) On determination of the contract in full or in part, the Engineer shall determine what amount, if any, is recoverable from the contractor for completion of the works or part of the works or in case the works or part of the works is not to be completed, the loss or damage suffered by the Employer. In determining the amount, credit shall be given to the contractor for the value of the work executed by him upto the time of cancellation or the value of contractor’s materials to be present so as to record the measurements in his presence. If the contractor fails to be present in response to the notice, the recording of measurements shall be proceeded with ex-parte and the measurements as recorded shall be binding the contractor. V) The Bank shall have the right to use contractor’s plant, machinery and materials on the balance work but shall not in any way be responsible for any damage or loss of the same and the contractor shall not be entitled to any compensation thereof. h.\D:\arch.06\FORMAT FOR TENDER TERMS & CONDITIONS.doc D:\D-Packages\Intranet-Correspondence\thane\sanpada\TENDER-Electrical.doc 12 APPENDIX TO THE CONTRACT DOCUMENTS Subject: Electrical Work at Sanpada Branch 1. Defect liability period : 12 months from the date of virtual completion of work. 2. Date of commencement : 3 days after the contract is accepted by the contractor 3. Date of completion : 30 days from commencement 4. Liquidated damages : a) 1% of contract amount per week / day of delay subject to . maximum of 10% of contract value. 5. Period of honoring final certificate : 45 days 6. Value of work for interim certificate : Rs.____________ 7. Period of honouring certificate : 15 days 8. Retention money : 8% of the bill value will be deducted from interim payments as retention subject to maximum security deposit, inclusive of EMD. 50% of the retention money so held shall be refunded after virtual completion and balance 50% after defects liability period. 9. Initial security deposit including : Rs._______-______ earnest money deposit already submitted. 10. Total Security deposit : 10% of the contract amount 11. Earnest Money to be submitted : Rs.3760/-(1% of the estimated cost of work ) demand draft or pay order on any Nationalised Bank drawn in favour of Union Bank of India payable at mumbai D:\D-Packages\Intranet-Correspondence\thane\sanpada\TENDER-Electrical.doc 13 PROPOSED ELECTRICAL WORKS OF UNION BANK OF INDIA AT SANPADA BRANCH NAVI MUMBAI. SCHEDULE OF QUANTITIES No. Description Qty. Unit Rate AMOUNT SECTION - A ELECTRICAL WORK 1 Supply,Installation,Testing,Commissioning of Main Power Distribution Panel (MPP) as follows : 1 Set Incomer a 1 No. 125A MCCB, 35kA, RL=80-125A with all standard accessories as follows: i) Thermal O/L Realease Range : 80-160A ii) Instantaneous magnetic S/C Trip iii) Rotary handle. iv) Shunt Trip . b Metering & Indications Ammeter class 1.5 with selector switch-1 set Voltmeter class 1.5 with selector switch-1 set 160A 4 pole Tinned & sleeved copper bus bars Indication lamps R, Y, B-22.5 dia cluster LEDs Outgoings c 63A TPN MCB - 5Nos., 40A DP MCB - 2 d Capacitor Bank, 3 Phase, 5Kvar -4 nos, 7.5Kvar- 1 no. APP type, Delta connected, self healing with microprocessor based relay & auto manual control The rate shall include all components, internal wirings & acceessories 2 Supply & laying of aluminium/ copper armoured cables fixed to walls, ceiling orr laid in ready- made trench as follows a 3.5 Core 70 sq.mm Armoured cable with bare 8 SWG G.I. earth wire 25 Mtrs b 4 Core 6 sq.mm Armoured Copper cable with bare 12 SWG G.I. earthg wire 50 Mtrs c 4 Core 10 sq.mm Armoured Copper cable with bare 12 SWG G.I. earthg wire 5 Mtrs d 3 Core 4 sq.mm Armoured Copper cable with bare 12 SWG G.I. earthg wire 45 Mtrs D:\D-Packages\Intranet-Correspondence\thane\sanpada\TENDER-Electrical.doc 14 e 2 Core 4 sq.mm Armoured Copper cable with bare 12 SWG G.I. earthg wire (for AC units) 50 Mtrs f 2 Core 2.5 sq.mm Armoured Copper cable with bare 12 SWG G.I. earthg wire (FOR External Lighting) 15 Mtrs g 2 Nos. 16 sq.mm + 6 sq.mm (Earth) PVC insulated FLEXIBLE Copper wires in flexible conduit. For UPS Input/Output 10 Mtrs h 4 Nos. 25 sq.mm PVC insulated FLEXIBLE Copper wires in flexible conduit. For Meter Leads. 8 Mtrs 3 Termination of the above cables with Heavy duty Cu. Lugs & Brass cable glands a 3.5 x 70 sq.mm 2 Nos. b 4 x 6/4 sq. mm 6 Nos. 15 2 x 4/2.5 sq. mm A/C side 11 Nos. Panel-11 10 Nos. 4 Supply, Installation, Testing & Commissioning of Distribution Boards recessed in walls/partitions, complete with MCBs/Isolators/ Bus bars and interconnections.No fabricated DBs shall be allowed. Only DBs of specified makes as per list of materials shall be used (DOUBLE DOOR IP42 Type) a) TPN as follows (Lighting/ Raw Power) 1 Each Incomer 40/63A, TPN MCB -1Nos. 40A, 2P RCBO -3Nos. Outgoing 16A/20A/25A SP MCBs -18 nos. b) TPN as follows (ACDB) 1 Each Incomer 40/63A, TPN MCB -1Nos. 40A, 2P RCBO -3Nos. Outgoing 16A/20A/25A SP MCBs -12 nos. c) SPN DB ( UPSDB)/ RAW DB 1 USP , 1 Raw 2 Each Incomer 40A DP MCB - 1 No. Outgoing 10 A/16A SP MCBs -6 Nos. 5 Point wiring through PVC conduits 25mm/20mm as IS 9537 part III with 2 Nos. of 1.5 sq.mm & 1 no. of 2.5 sq. mm (for earth) PVC insulated Copper Conductors with modular switches complete with all accessories as detailed in specification. The switch boxes shall be flush mounted with partition works or as directed by the architects & shall done co-ordination with interior furniture works. The dros to the switch board shall be concealed.The rate shall include circuit wiring from DB to switch & switch board to switch board. The ceiling rose shall be of three plate. D:\D-Packages\Intranet-Correspondence\thane\sanpada\TENDER-Electrical.doc 15 a) For primary light points/Fan points 30 Nos b) For Secondary light points 20 Nos c) For bell points with Ding-Dong Bell (primary) 1 Manager, 1 Rear side 1 Nos d) For Independent 6A plug points with 6A 3 pin switch socket combine 4 Nos e) For 6A switch socket 3 pin combined on the lighting switch board. 7 Nos. 6 Supply , Installation, Testing & Commissioning of 9" exhaust fans 1500 rpmof GEC make or cropmton , 230V Single phase. The rate shall include connection with 3 core 0.5 sq.mm flexible copper cable from ceiling to the exhaust fan. Toilet, Pantry 1 Nos. 7 Supply, Installation, Testing, comissioning of 2 x 36W CFL mirror optic fittings (Direct Indirect). The rate shall include 2 Nos of 36W CFL tubes.The fittings shall be fixed with screws to the frame & supported by chain to the ceiling. The fittings shall be recessed mounted in flase ceiling. The frame for mounting the fittings shall be provided by the false ceiling contractor. The rate shall include connection with 3 core 0.5sq mm. cable. Electronic ballast with THD less than 10 % and warm start. Make WIPRO, PHILIPS, GE, THORN 24 Nos 8 Supplying & fixing of 2 x 18w CFL spot light fitting with CRCA housing powder coated & highly purity Aluminium reflector, complete with electronic ballast & accessories. The rate shall include connection with 3 core 0.5sq.mm cable & CFL lamp. MakeWIPRO, PIERLITE, PHILLIPS, GE, THORN 15 Nos. 9 Supplying & fixing of 1 x 18w CFL spot light fitting with CRCA housing powder coated & highly purity Aluminium reflector, complete with electronic ballast & accessories. The rate shall include connection with 3 core 0.5sq.mm cable & 18w CFL lamp. Make WIPRO, PHILLIPS, GE, THORN 15 Nos. 10 Supplying & fixing of 1 x 36w patti type flourescent light fitting with CRCA housing powder coated housing with VPIT ballast & condenser & all accessories. The fittings shall be on PVC round blocks.The rate shall include connection with 3 core 0.5sq.mm cable & 36w FTL lamp. Make WIPRO,PHILLIPS, THORN, GE 5 Nos. D:\D-Packages\Intranet-Correspondence\thane\sanpada\TENDER-Electrical.doc 16 11 Supplying & fixing of 1 x 18w box type fluorescent light fitting with CRCA housing powder coated housing with VPIT ballast & condenser & all accessories. The fittings shall be on PVC round blocks. The rate shall include connection with 3 core 0.5sq.mm cable & 18w FTL lamp. Make WIPRO, PHILLIPS, THORN, GE 2 Nos. 12 Supply & fixing of 6/16A Power switch socket modular type complete with G.I. switch mounting box. Pantry, Printers, Xerox machine 8 Nos. 13 Supplying, Installation, Testing & Commissioning of T5LL28 Watts batten light fixtures as approved by the Architect with all fittings, fixtures, assessories etc complete10 Nos. 14 Preparation and commissioning of earth pit with 600 x 600 x 6 mm thick copper electrode with watering arrarangement, chamber, funnel, charcoal salt etc.The electrode shall be connected with 25 mm x 3 mm thick G.I.Strip and terminated into the chamber with nut bolt arrangement.The rate shall include cost of earthing strip upto the chamber. For UPS 2 No 15 Preparation and commissioning of earth pit with 600 x 600 x 6 mm thick hot dipped Galvanised electrode with watering arrarangement, chamber, funnel, charcoal salt etc.The electrode shall be connected with 25 mm x 3 mm thick G.I.Strip and terminated into the chamber with nut bolt arrangement.The rate shall include cost of earthing strip upto the chamber. For Main Earth 1 No 16 Supplying & laying of 25mm x 3mm thick GI earthing chamber to main power panel & terminating the same. The portition of the strip under- ground shall be laid to a depth of atleast 60cms. The portitions on building wall & upto the main panel shall be fixed with spacers & clamps. 5 mtr 17 Supply & laying of single core 10 sq.mm PVC insulated Copper conductor through PVC pipe, 20mm dia, Heavy guage, from earth pit to UPS DB laid to a depth of 30 cms or along wall/ceiling. The rates shall include cost of all material & accessories 80 mtr 18 Supply, installation, testing & commissioning of 20/25A Reyroll plug sockets with 3 pin Metal Top, Housed in metal board with 25A SP MCB, Make MDS/Siemens/Hagger 5 Nos. 19 Supply installation,testing & commissioning of 63 DP MCB in MS Box. Make MDS/Siemens/Hagger UPS out 3 No. D:\D-Packages\Intranet-Correspondence\thane\sanpada\TENDER-Electrical.doc 17 20 Supply installation,testing & commissioning of 40A/63A TPN MCB in MS Box. Make MDS/Siemens/Hagger UPS Main 1 No. 21 Supply & installtion of wall mounted fan. 1 Nos. 22 Supply, Installation, testing & Commissioning of 125A TPN SFU in sheet metal enclosure complete with 160A HRC fuses & cable end boxes. (AC23 duty). Make L&T/GE/Scheider. 2 Nos. 23 Supply, installation, testing, commissioning of Auto-cyclic timer board with IP 55 metal enclosure using contactors, timer switch, indicators etc. complete with all accessories for controlling A.C.units, panaflex external board lighting. 2 Nos. 24 Provision of temporary lighting with sufficient nos. of lights, power sockets and one electrician during the execution of work. The electrician shall be presenet in the branch during the work & banking hours or as and when requires by the branch. 1 Job TOTAL OF SECTION A RS. SECTION -B - COMPUTER WIRING 1 Preparation of trenches 12"/18" wide by carefully removing the floor tiles by machine cutting & removing the malwa below the tiles for laying raceways/conduits for power, telephones etc. The depth of the trenches shall be atleast 2 inches from the finished floor level or upto RCC of the slab. The rate shall include filling the trenches with rich mix of 1:2 PCC after laying ofthe raceways/conduits for smooth finish upto original tile level. The rate shall not include the cost of the raceways/conduits. 40 mtr 2 Supply and laying Raceways/Conduits in the trenches as detailed above or through partitions with all accessories, bends, pullwire etc.but excluding the floor mounted junction boxes which shall be paid separately. The metal/PVC conduits/Raceways shall be earthed with copper earthing clips at suitable intervals the distance between the data conduits & power conduits shall be maintained at atleast 6" apart. a) 25mm PVC conduits for power & telephone & security alarm HMS 250 mtr b) 20mm PVC conduits for power & telephone & security alarm HMS 50 mtr 3 Supplying and laying of PVC insulated copper conductors through already laid PVC conduit. D:\D-Packages\Intranet-Correspondence\thane\sanpada\TENDER-Electrical.doc 18 4 S & I of point wiring for UPS or stabilized power plug points on workstations / table for computers using 3 X 2.5 Sqmm copper conductor PVC wires pulled through already laid floor raceways and taken upto table top using PVC rigid or flexible conduits run within wooden/metal partitions . Each point consisting of 3nos of 6A , 3 pin sockets & 1 No 16A switch above table wired together forming one point 8 set 5 S & I of point wiring for Raw power plug points on workstations / table using 3 X 2.5 Sqmm copper conductor PVC wires pulled through already laid floor raceways and taken upto table top using PVC rigid or flexible conduits run within wooden/metal partitions . Each point consisting of 1no. of 6A , 3 pin sockets & 1 no. 6A switch wired together forming one point 9 set 6 Supply and fixing of data outlet, telephone socket modular type complete with chrome plated mounting box.The box shall be fixed in partitions/concealed in walls. The rate shall be inclusive of all accessories. a) 1No. Data outlet Box only, with top acrylic cover 3mm thk, with a cut out suitable for data venders (Data I/O will be provided by the Bank) 15 set b) 2 No. RJ11 telephone socket. 8 set c) 1No. RJ11 telephone socket 6 set 7 Supplying and fixing 300mm x 300 mm x 50mm deep MS junction boxes 14 gauge with top removable stainless steel plate of 14 guage. The junction boxes shall be treated for rust proof treatment with 2 coats of red oxide and spray painted for smooth finish. The junction boxes shall have slots on all sides suitable for Raceways/conduits. The junction boxes shall be laid in trenches for Raceways/conduits as detailed as above. The top cover shall be fixed with counter sunk screws. (for floor trenches) 4 Nos. 8 Supplying and fixing 250mm x 250 mm x 50mm deep MS junction boxes 14 gauge with top removable stainless steel plate of 14 guage. The junction boxes shall be treated for rust proof treatment with 2 coats of red oxide and spray painted for smooth finish. The junction boxes shall have slots on all sides suitable for Raceways/conduits. The junction boxes shall be laid in trenches for Raceways/conduits as detailed as above. The top cover shall be fixed with counter sunk screws. (for floor trenches) 6 Nos. TOTAL OF SECTION B RS. D:\D-Packages\Intranet-Correspondence\thane\sanpada\TENDER-Electrical.doc 19 SECTION C- TELEPHONE WIRING 1 Supply and fixing of 50 pair telephone MDF consisting of tag blocks in groups of 10pair krone,disconnector type, complete with metal enclosure powder coated,krone tag block mounting arrangement,telephone distribution chart and locking arrangement(for P&T EPABX ). 1 No 2 Supplying and fixing of krone tag blocks 50 pair as above 1 No 3 Supply & fixing of 25mm medium guage PVC conduits as per IS 9537 part III on walls, ceiling or through partitions with spacers and saddles as per standard practice 50 Mtrs 4 Supply and laying telephone cables 0.5 mmdia electrolytic tinned copper conductors PVC insulated and twisted pair with rip cord, through already laid PVC conduits/raceways. The rate shall include termination at both ends on tag blocks & ferruling i) 20 pair cable 40 mtr ii) 2 pair cable 100 mtr TOTAL OF SECTION C RS. SECTION - D - PUBLIC ADDRESS & MUSIC SYSTEM 1 Supply,Installation, Testing & Commissioning of public address / music system comprising of the following : a) Supply, installation & testing of 2 core, 24/0.2 SWG flexible tinned copper polythelene insulated & twin twisted copper cables for speakers, volume control etc. through 20mm PVC conduits medium guage. The rate shall include the cost of PVC pipes and cables. 70 Mtr b) Supply and fixing of ceiling mounted 4watts 8 ohms, 6 inch round speakers left & Right, for stereo effect with line transformer and required accessories, suitable for recess ceiling, with mounting box. 4 Nos. c) 250 watts RMS output capacity Amplifier workable on 220 / 240V, 50 C/S AC supply or 12V DC supply with minimum 4 mike inputs, 1 phone input & 1 aux / tape input. 1 No. d) Supply & installation of Chiago Radio unidirectional condenser microphone suitable for above amplifier, complete with cable, jacks connectors & Table mounted microphone stand. 1 No D:\D-Packages\Intranet-Correspondence\thane\sanpada\TENDER-Electrical.doc 20 e) Supply & Installation of DVD player . The catalogue of the quoted DVD player shall be submitted along with the offer. 1 No. f) Supply & installation of volume control suitable 4 watts 8 Ohms speakers. The volume control shall be flush mounted flush in suitable box. The Volume control shall be flush mounted in standard module Box. 1 No. TOTAL OF SECTION D RS. SUMMARY TOTAL OF SECTION -A Rs. TOTAL OF SECTION -B Rs. TOTAL OF SECTION -C Rs. TOTAL OF SECTION -D Rs. TOTAL OF SECTION A,B,C & D Rs. NOTE:- RATE SHALL BE INCLUSIVE OF GETTING ADDITIONAL REQUIRED LOADS SACTIONS FROM BEST /MSEB, SUBMISSION OF TEST REPORTS, APPLICATIONS ETC. INSTALLATION OF HIGHER CAPACITY METER, CONNETIONS ETC. NO LIASIONING CHARGES SHALL BE PAID FOR THAT. TOTAL Rs. LESS:DISCOUNT OFFERED ANY % Rs. GRAND TOTAL Rs. SIGNATURE & SEAL OF THE CONTRACTOR D:\D-Packages\Intranet-Correspondence\thane\sanpada\TENDER-Electrical.doc 21 APPROVED LIST OF ELECTRICAL MATERIAL Description Brand 11 KV CIRCUIT BREAKER PANEL ABB / SEIMENS / AREVA 11 KV / 0.4 KV TRANSFORMERS CROMPTON / KIRLOSKER / AREVA / SEIMENS BATTERY CHARGING PANEL KELTRON / NELCO BATTERIES EXIDE / AMCO / STANDARD / PANASONIC 11 KV Isolator and D O Fuses AMEI / ELLPRO / STERLING Capacitor L & T / DUCATI / EPCOS APFC relay L & T KHATAU / DUCATI / SYNTRON M.C.B. / RCCB / RCBO LEXIC / HAGER / ABB / MDS Distribution Boards LEXIC / HAGER / ABB / MDS Switch Fuse Units With HRC fuses GE / L&T / ABB Moulded Case Circuit Breaker (MCCB) ABB (T max) / L & T (D sine) / SIEMENS Air Circuit Breakers ABB (EMEX/L&T(C POWER) / SIEMENS Current Transformer / Meters / Voltage Transformers / Relays / Starters / Contactors / Selector Switch / Indicating Lamps L & T / SIEMENS / AUTOMATIC ELECTRIC / CONTROL & SWITCH GEARS / ABB Change Over Switches GE / L&T / HH ELCON / HAVELLS Cable Glands and Sockets SIEMENS / JAINSON / COMET PVC insulated Copper conductor wires FINOLEX / RR / POLYCAB Telephone Wires and cables FINOLEX / (RPG/BIRLA ERRICCSON POLYCAB Television Coaxial cable FINOLEX / RR /RPG / L&T PVC / XLPE Insulated 11 KV / 1.1 KV Cables UNIVERSAL /FORT CLOSTER / NICCO / FINOLEX/POLYCAB Switches and Sockets outlets (Conventional piano type) ANCHOR Switches and Sockets outlets (Modular type) LK Fuga / MK / MDS-MOSAIC Industrial outlet LEXIC / HAGER / ABB MIS Conduits and Accessories B.E.C./AKG/MK PVC Conduits and accessories AKG/BEC/CAP/SEIKO / PRECISION Fluorescent Tube Fitting PHILIPS /WIPRO Incandescent Light Fitting DECON/PHILIPS / BAJAJ / WIPRO Hpmv/hpsv/ halogen Lamp PHILIPS / WIPRO / BAJAJ / CROPTON GREAVES Ceiling Fans / Exhaust Fans CROMPTON / BAJAJ / USHA / KHAITAN Floor / Wall Raceways to date MK/ LK/ MDS Computer networking - outlet AMP/SYSTEMAX / LUCENT Electronic Energy Meters SECURE / L&T / ENERCON UPS EMERSON / POWERWARE / TATA LIBERT / DB ELECTRONICS Ceiling Rose holders ANCHOR Buzzers/Bell Push bell ANCHOR MCB Distribution Board MDS/LEGRAND/SIEMENS /HAGER HRC Switch Fuse nits SIEMENS ABB/GE/L&T Cable Glands/Lugs SIEMENS/DOWELLS Electronic Regulator MK/ANCHOR/ROMA/LEGRAND/MDS D:\D-Packages\Intranet-Correspondence\thane\sanpada\TENDER-Electrical.doc 22 Contractors SIEMENS/L&T/ABB/SCHNIEDER Geysers/water/heater SPHERE HOT /RACOLD/USHA AIR CONDITIONING UNIT (WINDOW / SPLIT / HIGH WALL / CEILING MOUNTED) VOLTAS / BLUE STAR / CARRIER / HITACHI / DAIKIN NOTE : Sr. No. Description 1. The choice of the final makes shall be made by the owner/ consultant 2. The samples or Cat.No. of all type of switches & light fittings should be approved before execution. D:\D-Packages\Intranet-Correspondence\thane\sanpada\TENDER-Electrical.doc Sector : Banking, Finance & Insurance State : Maharashtra For further Information Contact: Name : Union Bank E-Mail : romharshrazdan@unionbankofindia.com Phone Office : 022-25710446 Fax : 022-25704295 |
