Description Internal Furnishing of Premises BO Sant Pura Tilak Nagar, S.HPS Dhingra ZONAL MANAGER Punjab & Sind Bank, ZO-II B-38/39 Ind.Area Naraina, Phase-I, New Delhi-110028 Ph:011-25897834,25897835,25896481 PUNJAB & SIND BANK ZONAL OFFICE-II Naraina Ind. Area New Delhi. ANNEXURE –II (Details to be furnished for publishing the tender on Govt. site www.tenders.gov.in) 1.Tender Title : Tender for Internal Furnishing of Premises BO Sant Pura Tilak Nagar New Delhi. 2.Tender Ref.No : PSB/ZO-II/ Sant Pura/ 21.11.09 3. Product Category : Internal Furnishing of Premises 4. Sub Category : Nil 5. Tender Value_ INR 8,00,000/-___EMD__15,000/-_Document Cost_ 1,000/- 6. Tender Type : Work Contract 7. Enter Location Sant Pura Tilak Nagar New Delhi. 8. First Announcement : Date : 21.11.09 Time: 10-00 A.M. 9. Last Date of Document collection : Date : 11.12.09 Time: 03-00 P.M. 10.Last date for : Submission Date: 11.12.09 Time: 5-00 P.M. 11. Opening date : Date: 12.12.09 Time: 13-00 A.M. 12. Work description : Internal Furnishing of Premises of BO Sant Pura Tilak Nagar New Delhi. 13. Pre- Qualification : As per Tender Document 14. Contact details : Name : HPS Dhingra Designation : ZONAL MANAGER Address : Punjab & Sind Bank, ZO-II B-38/39 Ind.Area Naraina, Phase-I, New Delhi-110028 Telephone : 011-25897834,25897835,25896481 Email : zo.delhi2@psb.org.in Fax : (011) 25897836 2 2 Punjab & Sind Bank Zonal Office – II Naraina, New Delhi hereby invites sealed tenders for undertaking internal furnishing work at its BO Sant Pura Tilak Nagar New Delhi. Tender Document is placed below. Last date for submission of tender is 11.12.2009. Zonal Manager 3 3 TENDER DOCUMENT EMPLOYER : PUNJAB & SIND BANK ZONAL OFFICE-II B- 38/39 COMMUNITY CENTRE PHASE I NARAINA INDUSTRIAL AREA NEW DELHI. PROJECT : INTERIOR FURNISHING WORKS FOR THE B.O. SANTPURA TILAK NAGAR NEW DELHI. TENDER ISSUED TO : M/s LAST DATE : 11.12.09 - 1700 HRS EARNEST MONEY : Rs . 15,000 /- COST OF TENDER : Rs. 1000.00 Architects ANIL ASSOCIATES ARCHITECTS ,PLANNERS, ENGINEERS, INTERIOR DESIGN CONSULTANTS AA HOUSE C-330, SARITA VIHAR MATHURA ROAD NEW DELHI-110 076 TEL: 2694 1291, 2694 1292 FAX : 2694 1292 Email: associates.anil@gmail.com Mobile: 98 1000 7032 4 4 To SUB: TENDER FOR INTERIOR FURNISHING AND ALLIED CIVIL PLUMBING AND ELECTRICAL WORK AT PUNJAB & SIND BANK SANTPURA TILAK NAGAR DELHI. OUR REF.: PSB/ ZO-II/ SANTPURA/ 21.11.09 Dear Sir, 1. The sealed tenders are invited for the above said work by ZONAL MANAGER PUNJAB & SIND BANK, ZONAL OFFICE- II B- 38/39 , NARAINA IND. AREA NEW DELHI upto 1700 Hours on or before 11.12.09. The schedule, specifications and terms for the above said work is enclosed. 2. The sealed cover containing the schedule and the tender in original alongwith earnest money of Rs. 15,000 /- in shape of DD in favour of PUNJAB & SIND BANK, shall be submitted in the office of ZONAL MANAGER PUNJAB & SIND BANK, ZONAL OFFICE –II NARAINA IND AREA NEW ELHI. The cover shall super scribed as follows: “TENDER FOR INTERIOR FURNISHING AND ALLIED CIVIL WORKS AT PUNJAB & SIND BANK SANTPURA TILAK NAGAR BRANCH.” 3. The tender shall be opened at 1300 Hrs. on 12.12.09 in the presence of tenders/ or their representatives. 4. The tender shall be valid for 4 months from the date of the opening. The successful tenderer has to execute the agreement with the bank on stamp paper as per the format enclosed. 5. The ZONAL MANAGER PUNJAB & SIND BANK, ZONAL OFFICE- II NARAINA IND AREA NEW DELHI, Reserves the right that without assigning any reason thereof: (a) To accept or reject any tender in whole or in part. (b) To increase or decrease the quantities of any item and tenderer has to execute the same at the rate quoted. 5 5 6. The bank does not take any responsibility for the delay loss or non receipt of tender after dispatch. 7. The completion time shall be 40 days from date of award of work. 8. The date of completion of the job is the essence of this contract. The contractor is therefore requested to complete the job within the stipulated time. Any deviation with respect to time or specification to Bank’s prejudice it has right to: (a) Cancel/Rescind/Revoke the order. (b) Impose penalty upto 5% of the total value of job. 9. Contractors in their own interest are advised to visit the site & get themselves familiarized with the prevailing situations before submitting their rates. No claim whatsoever for ignorance, misunderstanding shall be entertained later. 10. The work is proposed to be done in the Occupied Area. Hence Contractor has to plan his work so as to General working of the offices/ shops in the adjoining area and the peace of the residential area is not effected. He may have to work only after business hours & during the nights. 11. The contractor shall be responsible for making good expeditious and workman like manner any defects, which may be found with in one year of the handing over the site, put to beneficial use. In case contractor fails to do so, the same would be got done at his cost and risk. The cost incurred by the bank shall be deducted from the retention money or any other dues. 12. Security deposit equivalent to 10% from each running bill shall be deducted and shall be returned only after expiry of defects liability period. 13. Rates quoted shall be inclusive of all taxes, levies, duties and all charges such as freight, insurance, octroi loading/ unloading, unpacking and moving the goods in position on site etc. for compete item. 6 6 14. The schedule of quantities is only approximate and all the work executed shall be paid for in accordance with the actual measurements as per relevant part of IS: 1200: 1974 or otherwise provided. 15. In case of any dispute, the same shall be referred to G.M. (GA) PUNJAB & SIND BANK, HEAD OFFICE RAJINDRA PLACE NEW DELHI and his decision shall be final and bindings on both the parties as per the provision of Arbitration Act. 16. It will be obligatory on the part of the Tenderers to sign on each and every page of the tender and all components of the tender. Conditional tender shall be summarily rejected. 17. The samples of all the material and work items shall be got approved from the Architect or his representative before proceeding further on. 18. The drawing contains sketches showing salient features details at the various scale indicating extent of work and specifications to be followed. These can be modified by the bank from time to time in accordance with technical requirements at the site. 19. Any damage done to the property of the bank during execution of the work shall be responsibility of the contractor and it shall be made good by him, at his cost to the entire satisfaction of Architect/Bank. 20. The Architects shall have full powers to get the material or workmanship etc. inspected and tested by an independent agency for its soundness and adequacy at the cost of contractor. 21. The contractor shall examine all drawings before quoting and commencing of actual work and report to the Architect/Bank any discrepancies for omission and shortcomings in the drawings. 7 7 22. The work shall be of highest standard both as regard to material and workmanship. Modern tools and first class latest techniques shall be employed for its execution. 23. The Income tax and sales tax or any other tax or Government levies shall be deducted by the Bank at source or as per the relevant laws as applicable. 24. The intending contractors are requested to clarify any doubts or any clarification regarding the specifications or any other matter pertaining to this tender before the submissions of the tender from the office of the ZONAL MANAGER PUNJAB & SIND BANK, ZONAL OFFICE-II NARAINA IND AREA NEW DELHI. on any working day. Any claim for the ignorance shall not be entertained by the Bank at the later date. Contractor shall also refrain form putting up any conditional offers, which may be rejected by the Bank. 25. All and any debris arising due to this work or allied works shall be cleared by the contractor as soon as work is completed on his cost. 26. MODE OF SUBMISSION OF TENDER The tenderers are requested to submit their offer in the following manner: i) Envelope marked "Number 1- Technical Bid " shall contain the Earnest Money Deposit and the following documents. a) Covering Letter to Tender. b) Book let super scribed "Tender Documents Part I and the letter indicating unconditional acceptance of the Bank Tender Conditions in total. The envelope must be wax sealed. 8 8 c) Completion Certificates that the tenderers have successfully executed at least three similar work of minimum value of Rs. 10.00 Lakhs each for Nationalized Banks/ Financial Institutions in last two years. The should also submit a Capability statement containing the details of infrastructure, support of men, equipment and finance available, Solvency certificate, Annual Turnover for the last 5 years, ITCC, PAN NO. Sales Tax no. Audited balance sheet of last three years, details of work executed and in hand with the name of employers, consultants, value of work, period of construction etc. All information should be supported with the documents. Bank reserves the right to verify the information submitted by the tenderers. iii) Envelope marked "Number 2 - Price Bid" shall contain only the price bid on the Tender Book let super scribed "Tender Documents" TENDER FOR INTERIOR FURNISHING AND ALLIED CIVIL WORKS AT PUNJAB & SIND BANK , SANTPURA NEW DELHI., and must be wax sealed. iv) Envelope marked number 1, & 2 shall be put in a large envelope of adequate size clearly subscribe with the tender no. It shall be sealed and marked to the ZONAL MANAGER PUNJAB & SIND BANK, ZONAL OFFICE-II B 38/39 NARAINA IND AREA NEW DELHI 28. Bank reserves the right to decline the issue of tender to any contractor without assigning reasons therefore. 29. The tenderer who download the tender documents from website may submit the tender cost along with the EMD in the envelope I in a separate Bank Draft. Thanking you, Sincerely yours ZONAL MANAGER PUNJAB & SIND BANK B-38/39 NARAINA INDUSTRIAL AREA NEWDELHI ENCL: AS ABOVE. 9 9 TENDER FORM Zonal Manager PUNJAB & SIND BANK, ZONAL OFFICE, B 38/39 NARAINA INDU. AREA NEW DELHI, New Delhi . Sub: Interior Furnishing of the Branch at SANTPURA TILAK NAGAR NEW DELHI.. Dear Sir: With reference to the tender invited by you for the above proposed work, I/We write this after having (a) Examined the designs, drawings, details, specifications, Bill of quantities, instructions to the tenderers, draft agreement and the conditions of contract annexed there to (herein after called the Contract Documents) relating to above proposed work. (b) Visited and examined the site of the proposed work and acquired the requisite information as affecting the Tender. I/We undersigned hereby offer to carry out the proposed work in strict accordance with the contract documents for the consideration to be calculated in terms of the priced Bill of the quantities. I/We undertake to complete the whole of work as per the attached appendix from the date of issue of an intimation by you that our Tender has been accepted and upon receiving possession of the sites I/We further undertake that on failure subject to the conditions of the Contract relating to extension of time I/We shall pay agreed Liquidated damages to the employer the sum named in the Appendix to the Conditions of the Contract as `Liquidated damages' for the period during which the work shall remain incomplete. I/We hereby deposit with you as Earnest Money Rs. 15,000 /- in form of a demand draft on no interest and I/We do hereby agree that this sum shall be forfeited in the event of the employer accepting my/our Tender and I/We fail to take up the Contract when called upon to do so. I/We hereby agree that unless and until a formal agreement is prepared and executed in accordance with the Articles of Agreement, the tender together with your letter of acceptance thereof shall constitute a binding contract between us. It is also clearly understood that the Employer/Architects reserves the right to reject any tender including the lowest without assigning any reasons whatsoever for such rejection. I/We agree to keep the offer open for 6 months from the due date of submission of tenders. Yours faithfully, (Signature & Seal of the Tenderer) Place: Date: 10 10 ARTICLE OF AGREEMENT AN AGREEMENT made this ____________________ day of _________ 2009 between PUNJAB & SIND BANK , a body corporate constituted under Banking Companies (Acquisition and Transfer of Undertakings) Act, 1970 having its Zonal Office at B-38/39 COMMUNITY CENTRE PHASE I, Naraina Industrial Area New Delhi . (hereinafter referred to as the "Bank") of the one part and __________________________ of __________________________hereinafter referred to as the "Contractor") of the other part. WHEREAS IT IS AGREED: 1. The Contractor shall carry out, construct and complete the work interior furnishing of the branch at SANTPURA New Delhi. for the Bank on the terms and conditions herein contained and according to the General Conditions of Tender Specifications and Schedule of rates and plan attached, and instructions to be given by and under the supervision of and to the entire satisfaction of the Bank's authorized representative at New Delhi and has by way of earnest money deposit/security money deposit for the due fulfillment of this obligations hereunder, lodged with the Bank a deposit of Rs. 15000.00 by a Bank draft as required in Clause 1.11 of the Notice Inviting Tenders to the Bank's satisfaction. 2. Inspection of Site: The Contractor has inspected the Site before submitting his tender and has satisfied himself as to the nature of the work to be executed on the site. Any difficulties which the Contractor may come across in the course of the work shall neither in any way relieve him from fulfilling the terms of this agreement nor entitle him to claim or receive extra payment, unless the Bank's authorized representative is of the opinion that such difficulties could not have been foreseen. 3. Supply of Material/Labor: The Contractor shall furnish all labor, materials, equipment, tools, tackles, water, electricity & every thing necessary for the construction & completion of the work except such materials as will be supplied by the Bank which are detailed in Schedule attached hereto. The Contractor will assume all responsibility for the safety, protection & accounting of all material/equipment supplied to the Contractor & the work during construction. The details & dimensions shown on the plan shall be adhered to by the Contractor & no alteration shall be made therein by the Contractor without obtaining previous approval in writing from the authorised representative. The Contractor shall prepare his own details and shop plans, templates, patterns and other data where required, and shall adhere to all measurements and alignments as shown on the plan. The contractor shall submit to the Office of the Bank the contract periodic progress report and photographs of his work. All materials supplied by the Contractor shall be of the best quality, conforming to the required specifications and will be subject to the approval of the Bank's authorized representative. All such materials as shall not be approved, shall be removed at once by the Contractor at his own expense. The Contractor shall also arrange for and/or carry out test on all materials as per ISI . If so desired by the Bank, the Contractor will frame, in favour of the Bank, a guarantee indemnity of a Scheduled Bank, in respect of any loss/damage to the Bank, arising from any failure of the Contractor to discharge his responsibility for the safety and protection of all material/equipment supplied by the Bank and of the work during execution. 4. Damage on account of incomplete work: The Contractor shall commence the work immediately on receiving written instructions to that effect. The work will be progressed in accordance with the agreed schedule and whole work shall be completed and handed over ready for use within separately agreed time period from the date of commencement of work (time being of the essence), failing which the Contractor shall pay or allow the Bank 0.5% of the actual Contract value per week subject to a maximum of 5% of the total actual contract value as damages for extra time taken until the work is completed and handed over. Such damages may be deducted by the Bank from any money due to the Contractor. 11 11 5. Termination of Contract: In the event of the Contractor failing to keep to the agreed scheduled of work, or in the event of the Contractor failing to complete the work within the stipulated period, the Bank may notwithstanding the provisions in Clause 4 above, terminate this agreement forthwith and employ at the Contractor's cost, another contractor or a sufficient number of workmen to complete the work in which event the damages specified in Clause 4 above shall not apply from the date this agreement is terminated. 6. Defective work/materials: If any part of the work done by the Contractor shall be found defective in workmanship or if bad or inferior materials have been used. The Contractor shall at his own risk and cost demolish all such defective work and rebuild the same and/or replace the bad or inferior materials used, to the satisfaction of the Bank's authorized representative. The decision of the Bank's authorized representative in this regard shall be final and binding on the Contractor. In case of default of the Contractor to remove the defective work and rebuild the same or replace the bad or inferior materials as aforesaid, as directed by the Bank's authorized representative, the Bank shall be entitled to employ anyone else to carry out the same and recover all expenses incurred in this regard from the Contractor. 7. Substitution of Contractor: If the Bank finds it necessary to employ and other person(s) in terms of Clauses 5 and/or 6 above then the Bank may deduct and retain from out of the sums due to the Contractor all such sums of money as may be required to pay or to reimburse themselves in respect of the expenses which they may have to pay or have incurred in getting the work so done and if such expenses be more than the amount due to the Contractor, then the difference shall be a debt recoverable from the Contractor by the Bank. The Contractor shall not do or cause to be done any act, manner or thing, that would prevent the person(s) so employed by the Bank from doing their work. On termination of the agreement as aforesaid, the Contractor shall at his own risk and cost remove from the work-site within the time prescribed by the Bank all materials, tools, equipment which the Bank considers are not useful for its requirements. If the Contractor does not remove the materials within the time prescribed, the Bank may remove and sell the same holding the proceeds less the cost of storage, removal and sale, to the credit of the Contractor. Should the Bank incur any loss in respect of the sale, it shall be entitled to recover the same, from the Contractor. The Bank shall however be entitled to purchase the materials inspected and approved as useful for its requirements, at the prices then prevailing. 8. Inspection of work: During progress of the work, the Bank Engineer or any other representative of the Bank and Architect shall be entitled at all times to have access to and inspect the work. 9. Supervision: The Contractor shall provide one or more competent and technical supervisors duly and fully authorised to act on his behalf in all matters relating to the works to be carried out under or any other matter concerning this agreement and who shall at all times be present at the works when any work is in progress. Such supervisors shall be persons of known experience and be approved by the Bank authorized representative before they are permitted in any way to take charge of, or superintend any operation of the works. Any directions, explanation, instructions or notices in connection with the work given by the Bank's authorized representative to the supervisor or any one of them shall be deemed to have been given to the Contractor. 10. Payment for work done: During the progress of the work, the Contractor, at the sole discretion of the Bank's authorized representative may receive interim payment upto a maximum of 90%. proportionate to the amount of work per formed, after such work has been inspected and approved by such representative. Payments of the final bill will be made after adjusting the interim payments, and retention money as follows will be deducted and retained for a period of twelve months to safeguard against defects arising out of faulty workmanship/materials/provided by the Contractor and against any other claims against the contractor from any other reason whatsoever. a. Payment for each of the running bill of the Contractors shall be limited to 90% of the value and works certified. b. At the end of the Contracted works, 50% retained value as above will be converted to Retention money, for a period not less than twelve months. 12 12 11. The Contractor must submit his final bills in duplicate based on measurements jointly recorded by Architects Engineer and with the Contractor's authorised Representative, All payment against the bill will be made by Cheque and such payments shall be subject to deduction of income tax & Sales tax as may be applicable from time to time. 12. The Bank-in consideration of the Contractor constructing and carrying out the work shall pay the Contractor at the rates given in the attached Schedule ,subject to deductions, retention and abatements, if any to be made there-from. The payment in all cases will be in accordance with the actual quantities, based on the measurements as specified in Clause 11 above recorded by the Bank's Engineer in-charge and certified by the Architect. 13. Subletting Contract: The Contractor shall not without the prior written consent of the Bank first had and obtained sublet or assign this Agreement or any part there of PROVIDED ALWAYS that any consent given by the Bank for signing or subletting will not relieve the Contractor from the full and entire responsibility of his obligations under this Agreement and/or instructions issued to him. 14. Workmen's Compensation Liability: The Contractor, his heirs, executors and administrator (and in the case of a Limited Bank, its successors and assigns) shall hold the Bank harmless and indemnified from and against all claims, costs and charge for which the Bank shall be liable under the workmen's Compensation Act, and any enactment for the time being in force in that behalf and any amendments thereof and the expenses to which it shall be put there under, both in respect of personal injuries (within the meaning of the said Act) to the employees and servants of the Contractor sub-contractors, if any, and/or permitted assigns, arising out of or occasioned during the currency of this Agreement, through the acts, or omissions whether due to negligence or otherwise of the Contractor, sub-Contractor(s), permitted assigns and also in respect of the personal injuries (as understood under the said Act,) to the servants and employees of the Bank arising out of or occasioned through, the acts and commissions whether due to negligence or otherwise, of the Contractor, sub- Contractor(s) permitted assigns and/or his servants and employees in carrying out any of the provisions of this Agreement. The Contractor shall further indemnify the Bank against such claims from third parties in respect of injuries arising out of or occasioned through the acts and omissions, whether due to negligence or otherwise, of the Contractor, Sub- Contractors, permitted assigns and/or his servants and employees in carrying out any of the provisions of this Agreement. 15. Liability under Employees State Insurance Act: Whenever the Bank is required to pay contributions in respect of the workmen or employees engaged or employed by or through the Contractor, his Sub-Contractor or permitted assigns, under the Employees State Insurance Act or the Rules and Regulations, made there under either as the Principal Employer or otherwise howsoever, the Bank shall be entitled to recover from the Contractor such contributions which the Bank may pay. The Contractor will discharge his responsibilities under the Employee's State Insurance Act, 1948 as an immediate employees engaged or employed by him for the execution of work or as the next immediate employer in case he has sublet or assigned the Agreement or the instructions as provided herein above. The Contractor acknowledges the rights of the Bank to recover the amount of the contributions paid by it in the first instance in respect of the employees employed by or through him (the Contractor) or by his Sub-Contractor or permitted assigns, as well as the employees' contributions if any either by deduction from any amount payable to him by the Bank under any contract or as a debt payable by him to the Bank. 16. Statutory Requirements: The Contractor shall conform to provisions of Acts of Parliament or State Legislatures and to any bye-laws, rules, orders or notifications of any Government, Municipal or Local authority for the time being in force affecting the work undertaken by him and will give all necessary notices to and obtain requisite sanction and permits of and from the Municipal and any other authority in respect of the said work of the materials to be used thereat and generally will comply with building and other regulations of such authorities and will keep the Bank indemnified against all claims, penalties and losses that may be incurred by it by reason of any breach by the Contractor of any statutes bye-laws, rules, regulations, notifications etc. 13 13 "The Contractor undertakes to ensure due and complete compliance with all laws, regulations, rules etc. whether of the Central Government or the State Government or of any other competent authority applicable to the workmen employed or whose services are otherwise availed of by the Contractor whether in connection with the construction work at the site or otherwise. The Employer shall have the right to inspect the records maintained by the Contractor concerning such workmen from time to time and the Contractor shall whenever require by the Employer produce such records as the Employer may call upon the Contractor to produce for the Employer's inspection in order to ascertain whether or not the requirements of all such laws, regulations, rules etc. have been complied with by the Contractor. In event of any contravention of such laws, regulations, rules etc. coming to light whether as a result of such inspection or otherwise to effect such compliance within such time as the Employer may prescribe in that behalf and in the event of the Contractor failing to effect such compliance within the time prescribed by the Employer then the Employer shall without prejudice to his rights be entitled to withhold from the amount payable to the Contractor any amount payable to the workmen under any such laws, regulations or rules to make payment thereof to the workmen. The employer shall also have in that event the right to terminate the contract with immediate effect and to exercise powers reserved to the Employer under the contract as a result of termination." 17. Clerical errors to be rectified: Neither party shall take any advantage of any clerical error or mistake which may creep in or occur in the specifications, schedule of rates, plans instructions tenders or any other papers supplied to or by the Contractor in connection with the work, but such clerical error or mistake shall be brought to the notice by the one to the other without any loss of time and same shall be rectified. 18. "The parties to this agreement shall not be responsible for any failure of performance or delay in performance of their obligations hereunder if such failure or delay shall be a result of any Government directive relevant to this agreement or due to war, hostility, act of public enemy riots or civil commotion, strikes, lock-out, fire, floods, epidemic or acts of God, arrests and restraints of rulers and people, political or administrative acts of recognized or defector governments, import or export restriction compliance with orders of any governmental/local authority or any other cause or causes beyond their control." 19. Jurisdiction: This agreement shall be deemed to have been made in Delhi and shall be construed according to the laws of India and the performance by the Contractor of and act on his part herein contained shall be considered due in Delhi for the purpose of Jurisdiction. In witness whereof the said contracting parties have set hands and seals on the day and year first herein above witness. Witness EMPLOYER Witness CONTRACTOR 14 14 SECTION III SPECIAL INSTRUCTIONS TO THE TENDERERS 1. The material and workmanship shall conform to C.P.W.D. specifications 1977 Volume I & II and the relevant Indian Standards Codes of practice and or as specified by the Architect. 2. The samples of all the material and the work items shall be got approved from the Architect or his authorized representative in advance before proceeding further on the work. 3. The drawing contains the sketches showing salient details at various scales indicating the extent of work and specifications to be followed, these can be modified from time to time in accordance with technical requirement at the site. 4. The prospective contractor, on intimation on acceptance of tender must submit a progress net-work of the complete work based on bar-chart within four days as such, or modified with the consent of the contractor shall form a part of the agreement. 5. The work shall be of highest standard, both as regard its design and workmanship. Modern tools and first class latest techniques shall be employed for its execution. 6. Any damage done to the property of bank during the execution of the work shall be the responsibility of the contractor and it shall be made good by him, at his cost of entire satisfaction of the Architect/Bank. 7. The contractor should employ adequate labour to complete the work with in the specified time. No claim for the labour shall be entertained. The contractor shall also make his own proper arrangement for welfare, housing and safety of his material and labour. 8. The Architect shall have full powers to get the material or workmanship etc. inspected and tested by an independent agency for its soundness and adequacy at the cost of contractor. 15 15 9. The contractor shall examine all drawings before commencing the actual work and report to the Architect/Bank, any discrepancies for omission and short comings in the drawings or when they conflict with other works, or with each other. 10. The contractor shall visit the site of the work and shall satisfy himself as to the conditions under which the work has to be performed. He shall also check and ascertain the location of the existing structure or equivalent or another, which may affect the work. No claim, made in ignorance or under misunderstanding of the site conditions or on ground of insufficient description shall be entertained. 16 16 SECTION IV SPECIAL CONDITIONS & SPECIFICATIONS FOR ELECTRICAL WORKS 1. The work shall be carried out in accordance with General Specifications for Electrical Works (Part I – Internal – 1972 and Part II – 1974) as amended upto date. All installations shall comply with the requirements of the Indian Electricity Rules 1956 as amended upto date. 2. All materials to be arranged by the contractor for use in the work shall be of approved make and shall be as per Relevant Indian Standard Specifications. Where it is mandatory to use I.S. Marked materials, the same shall be arranged by the contractor accordingly. 3. Bad workmanship is liable to be rejected. 4. The contractor/his supervisor will be bound to sign the site order book and to carry out the instructions given therein. 5. The contractor shall get the approval of the Architect or his authorized representative regarding the route of conduits. No. of runs, diameter of conduits, no. and size of wires, locations of pull boxes, route of cables in ground/wall for electrical / security system/telephone works covered herein. 6. The contractor shall employ the technical staff as per clause 36 II of the contract documents for electrical works separately, during the execution of the work. 7. All repairs and patch work, if any shall be neatly carried out to match with the original fitting and to the entire satisfaction of the Architect. Any damages to the building due to execution of the work shall have to be made good immediately by the contractor at his own cost. 17 17 8. The contractor shall make his own arrangement at his own cost for all general and special electrical tools and plants required for electrical work. Entire safety precautions during installation shall be taken as per relevant I.S., I.E. Rules and C.P.W.D. Specifications. 9. Adopter boxes, wherever used, shall be of not less than 16 SWG M.S. Sheet. 10. a. The telephone conduits shall be laid with G.I. fish wires kept pulled in for pulling of at least 1000mm extra at ends. b. Main junction box for telephone conduit system shall be mounted at a height so that the top of box does not exceed 1.65 metres from the floor level and in a suitable location for working by the staff. c. Sockets, base, boxes, conduits, cable glands, ducts and all other materials not included elsewhere but required for the work shall be provided for by the contractor. 11. It shall be the contractor’s responsibility to get the electrical installation. Works inspected by the local Statutory Authorities, Fire Officer and such other officials. No extra payments/claims are allowable on this account. 12. The contractor shall obtain and pay for all permits, licenses and certificates for approved required by all relevant Authorities and Organizations. All work of the contractor shall conform to the requirements of the local codes. 13. The work shall be carried out as per regulations and in best workman like manner by licensed persons. The name of licensee person working in the installation shall be furnished to the Architect prior to the commencement of the work. 14. It is brought to the attention of the contractor that : a. All electrical portable tools should be either 240 Volts double insulated or 50 Volts via Transformer. b. The contractor has to supply all necessary ladders/steps which must be in good safe condition. 18 18 c. Entire safety precautions during installations shall be taken as per relevant I.S., I.E. Rules an as per C.P.W.D. Specifications. 15. Sub-Distribution Boards shall be equipped with miniature circuit breaker. Miniature circuit breakers shall have adequately sized terminals for the out-going leads. Distribution Board shall have adequately rated phase and neutral bus-bars of high conductivity electrolytic Aluminum with adequately sized terminals or clamps for the incoming conductor. Sub-Distribution Board shall have an earth bar with necessary numbers of terminals for connecting the earth continuity conductor associated with the various circuits supplied from the board. Each distribution board shall have a circuit schedule pasted on otherwise permanently fixed inside the cover stating the designation and details of circuits controlled and the rating of the miniature circuit breakers. The board shall be constructed of the miniature circuit breakers. The board shall be constructed of the sheet steel and provided with the removable conduit entry plate at top with gasket door arrangement. Non flammable insulating barriers shall be provided between poles and phases and al live parts protected with non flammable insulating shields to prevent accidental contact while replacing or operating the miniature circuit breakers. 16. All electrical work shall be carried out along with the progress of Interior works. Any debris due to electrical works shall be cleared by the Contractor as soon as the work is completed on his cost. 19 19 INTERIOR DECORATION & FURNITURE WORK One of the following makes of the material shall be used. The contractor will have to get the sample approved from the Architect whose decision shall be binding on the contractor. The condition is also applicable for any material not mentioned in the specifications or schedule of work. No deviations are allowed in these even during/after Tender. 1. Board/ply - National/ALPRO/ Archidply 2. Pre Laminated Board - Novapan./ Archidply 3. Plastic Laminated Sheet - Formica./EQ./ Archidply 4. Aluminium Section - Indal. 5. Door closers/floor spring - Everite. 6. Hinges/drawer slides - Earl-Bihari Pvt. Ltd. 7. Glue for fixing commercial - Pidilite (Fevicol). Board 8. Glass - H.P.G. 9. Mortice lock & night latch - Godrej 10. Venetian blinds - “Vista Levellor”. (Vertical/horizontal) 11. Vinyl flooring (2mm thick) - BHOR (Marblex). (Heavy duty, homogenous) 12. Upholstery - Bhor Bilbio 13. Synthetic enamel - Berqer. 14. MDF Board - NUWOD. 15. Tile Naveen/ Bell/ Kajaria 20 20 b. ELECTRICAL WORK 1. Switch & sockets - Plate Type – CPL. 2. Pipe (PVC) - Hindustan. 3. Telephone Cable - Delton. 4. Wires - National. 5. MCB’s - MDS. 6. DB’s - MDS. 7. Plug & socket - MDS. 8. Fluorescent Fixtures - Crompton./PHILLIPS 9. Box type fitting - Crompton. 10. MCCB’s - Havels. 11. Box Metallic - Galvanised 12. ELCB - English Electric 13. Halogen & spot light - Decon. Light Fitings 14. Cables - Grandlay. 15. Compression Glands - Dowell 16. Thimbles - Dowell 17. Fans - Crompton C. CIVIL WORK 1. GI pipe - Jindal (medium Class.) 2. GI Fittings - Unik. 3. CI Pipes & Fittings - RIF. 21 21 APPENDIX Defect Liability Period One year from date of completion. Date of Commencement The 3RD day after the date on which the Bank issues written orders to commence the work or from the date of handing over the site whichever is later. Period of Completion Forty days from date of award of work Value of work for interim Rs. 5 Lakhs Penalty for delay Rs. 5000/- per day Retention Money 10% of the bill amount including EMD. CONTRACTOR ZONAL MANAGER PUNJAB & SIND BANK, ZONAL OFFICE -II B 38/39 NARAINA IND AREA NEW DELHI 22 22 SPECIAL CONDITIONS 1. The work shall be carried out as per specifications in tender schedules/CPWD specifications 1977 alongwith the latest correction slips. In case of doubts the decision of the Bank shall be final and binding on the Contractor. 2. The General Conditions of Contract and standard contract form for the work will be followed as per Circular No. ADV/(C)/Gen-53/71/CIR/103-73 dated 6th February 1973 issued by the Bureau of Public Enterprises, Ministry of Finance with latest modifications and as amended till date. 3. Contractor shall be responsible for any damage to the equipment or structure injury to personnel during the progress of the work and he shall be liable to pay such compensation may be decided by the PUNJAB & SIND BANK in respect of such damages/injuries. 4. The serviceable materials out of the dismantled materials will be property of PUNJAB & SIND BANK and shall be properly stacked by the Contractors as directed by the Manager-in-Charge on the serviceability of the dismantled materials shall be final and binding on the contractor. 5. All labour employed by the Contractor shall be covered by workmen’s compensation Act. Any death, injury or mishap to the workmen of the Contractor will entirely be at the Contractor’s responsibility and Bank shall not be liable to pay any damages for the same. 6. The Contractor shall give his permanent account number (from the income tax department). 7. For the purpose of adjustment of the rise in price of labour the amount of labour will be considered to be 20% (twenty percent) of the total cost of the balance work at the time of promulgation of such law for modification. The Contractor shall quote their tender on the basis of labour rates in force as on the date of tender. 23 23 8. Guarantee of minimum 5 years will have to be given by the Tenderers for the water proofing treatment and indemnity bond for the purpose to be executed before release of the final payment/Security Deposit if job involves water proofing work. 9. The work shall be carried out as per Indian Electricity Rules. 10. General Specifications of the work can be inspected in the office of the Architects 11. Anil Associates will be the Architects for the subject work. 12. All woodwork to be painted with approved anti termite paint and fire proof paint whether mentioned or not in the schedule. Nothing extra shall be paid for the same. CONTRACTOR Anil Associates Architects Tel; 9810007032 Sl. No. Description of Item Qty. Unit Rate (Rs.) I fig. Rate (Rs.) in words Amount (Rs.) Section A : Furnishing Work 1. FALSE CEILING (GYPSUM CEILING) : Providing and fixing 12.5mm thick gypsum false ceiling as per direction of the Architect. Rate shall be inclusive of providing and fixing 18 gauge GI framework from India Gypsum at the distance of 600 mm c/c (max) both ways. Rate shall be inclusive of any vertical ceiling part, spot, tube light, fans, AC grills, fire and security systems cutouts with framing, and finishing with necessary jointing compound and 2 coats of plastic emulsion paint over a coat of primer. Manufacturer’s guidelines to be followed strictly. 120 Sq.m BILL OF QUANTITY FOR INTERIOR WORK INCLUDING FURNISHING, ELECTRICAL & CIVIL WORK OF PUNJAB AND SIND BANK , SANTPURA TILAK NAGAR NEW DELHI BRANCH . 11/20/2009 boq1 Anil Associates Architects Tel; 9810007032 Sl. No. Description of Item Qty. Unit Rate (Rs.) I fig. Rate (Rs.) in words Amount (Rs.) BILL OF QUANTITY FOR INTERIOR WORK INCLUDING FURNISHING, ELECTRICAL & CIVIL WORK OF PUNJAB AND SIND BANK , SANTPURA TILAK NAGAR NEW DELHI BRANCH . 2. Solid Partition (Partition Type – 1 as marked in the drawing ) : Providing and fixing partition framing upto ceiling level. Framing shall consist of 50 x 50 mm wood member, at 600 mm c/c bothways horizontally and vertically. Above false ceiling, alternate vertical sections to be extended upto main ceiling and to be fixed with MS cleats. Framing to be covered on both sides with 6 mm thick BWP ply finished with 1mm thick laminate of approved shade and colour, necessary groove work, beadings, moulding and 75 x 12 mm t.w. skirting duly polished. The item is to be finished complete in all respects. (Tenderer should visit the site and check the actual floor height – Partition to be measured upto false ceiling height excluding door opening for Billing purpose) 20 Sq.m 11/20/2009 boq2 Anil Associates Architects Tel; 9810007032 Sl. No. Description of Item Qty. Unit Rate (Rs.) I fig. Rate (Rs.) in words Amount (Rs.) BILL OF QUANTITY FOR INTERIOR WORK INCLUDING FURNISHING, ELECTRICAL & CIVIL WORK OF PUNJAB AND SIND BANK , SANTPURA TILAK NAGAR NEW DELHI BRANCH . 3. FULL HEIGHT PARTLY GLAZED PARTITION (Partition Type – 2 as marked in the drawing ): Providing and fixing partition framing upto ceiling level. Framing shall consist of 50 x 50 mm wood member, at 600 c/c bothways horizontally and vertically. Above false ceiling alternate vertical sections to extend upto main ceiling and to be fixed with MS cleats. Framing to be covered on both sides with 6mm thick BWP ply finished with 1mm thick laminate, necessary groove work, beadings, moulding and 75 x 12 mm t.w. skirting duly polished. Upto a height of 900 mm from FFL and from 2100 mm upto the false ceiling, the partition should be made solid / fully blocked; from 900 mm to 2100 mm clear glass of 8 mm thickness etched as per direction of the Consultant fixed with t.w. moulding of 19 x 35. The item is to be finished complete in all respects. (Tenderer should visit the site and check the actual floor height – Partition to be measured upto false ceiling height excluding door opening for Billing purpose). 18 Sq.m 11/20/2009 boq3 Anil Associates Architects Tel; 9810007032 Sl. No. Description of Item Qty. Unit Rate (Rs.) I fig. Rate (Rs.) in words Amount (Rs.) BILL OF QUANTITY FOR INTERIOR WORK INCLUDING FURNISHING, ELECTRICAL & CIVIL WORK OF PUNJAB AND SIND BANK , SANTPURA TILAK NAGAR NEW DELHI BRANCH . 4. LOW HEIGHT PARTLY GLAZED PARTITION (Partition Type – 3 as marked in the drawing ) : Providing and fixing partition framing upto total height of 1500 mm. Framing shall consist of 50 x 50 mm wood member, at 600mm c/c bothways horizontally and vertically. Framing to be covered on both sides with 6mm thick BWP ply finished with 1mm thick laminate upto 1050 mm height, necessary groove work, beadings, moulding and 75 x 12 mm t.w. skirting duly polished and above 900 mm level, glazed by 8mm thick 300mm high glass etched as per approved design upto 450 mm height. The item is to be finished in all respects. (Partition to be measured excluding door opening for Billing purpose). 6 Sq.m 11/20/2009 boq4 Anil Associates Architects Tel; 9810007032 Sl. No. Description of Item Qty. Unit Rate (Rs.) I fig. Rate (Rs.) in words Amount (Rs.) BILL OF QUANTITY FOR INTERIOR WORK INCLUDING FURNISHING, ELECTRICAL & CIVIL WORK OF PUNJAB AND SIND BANK , SANTPURA TILAK NAGAR NEW DELHI BRANCH . 5. MAIN ENTRANCE DOOR : Providing and fixing fully glazed pivoted door at the main entrance. Door shall consist of 125 x 50 mm CP teakwood for top rail and 175 x 50 mm CP teakwood for bottom rail and 12mm toughened glass, etched as per design in between. Rate should be inclusive of approved locking systems, 1 pair SS handles, single action floor spring with base plate, miscellaneous hardware items and melamine polish (sprayed) of rails all complete. Opening size 1050 x 2100 mm. (1 no.) Payable in Sq.m. 8 Sq.m 6. FLUSH DOOR : Providing and fixing in position 35 mm solid core flush door finished with 1mm thick laminate as per design on both sides duly polished, t.w. lipping on two vertical and horizontal edges having medium duty door closer, cylindrical lock, door stopper, brass hinges, etc. Also providing 75 x 62.5mm second class t.w. frame having t.w. lipping fixed in either surface of the frame duly polished with 3 coats of lacquer melamine and fixed to the partition frame. 6 Sq.m 11/20/2009 boq5 Anil Associates Architects Tel; 9810007032 Sl. No. Description of Item Qty. Unit Rate (Rs.) I fig. Rate (Rs.) in words Amount (Rs.) BILL OF QUANTITY FOR INTERIOR WORK INCLUDING FURNISHING, ELECTRICAL & CIVIL WORK OF PUNJAB AND SIND BANK , SANTPURA TILAK NAGAR NEW DELHI BRANCH . 7. PARTLY GLAZED DOOR : Providing and fixing in position 25 mm solid core panel door finished with 1mm thick laminate on both sides upto 1050 mm height, t.w. lipping on two vertical and horizontal edges, medium duty door closer, cylindrical door lock, door stopper, etc., 75 x 62.5mm second class t.w. frame with t.w. lipping, 8 mm thick glass with necessary etching and / or frosting to be provided as per design / directions, fixed with wooden mouldings from both sides. All exposed woodwork to be melamine polished. The work should be finished as per specification, design and completed in all respects. 6 Sq.m 8. FIXED GLAZING : Providing and fixing in position 12 mm thick glass, etched as per design fixed in 50 x 50 mm wooden framework with necessary t.w. moulding in two pieces in front of the cash / one window team as per design. 10 Sq.m 11/20/2009 boq6 Anil Associates Architects Tel; 9810007032 Sl. No. Description of Item Qty. Unit Rate (Rs.) I fig. Rate (Rs.) in words Amount (Rs.) BILL OF QUANTITY FOR INTERIOR WORK INCLUDING FURNISHING, ELECTRICAL & CIVIL WORK OF PUNJAB AND SIND BANK , SANTPURA TILAK NAGAR NEW DELHI BRANCH . 9. COLLAPSIBLE GATE : Providing and fixing collapsible gate made of best quality SRI Mills gate channel with 18 mm. x 5 mm. cross members with top fixed in tee and bottom runners made of 40 mm. x 6 mm. flats and 40 mm. x 12 mm. x 25 mm. flats finished with 1 coat of Black Japan and enamel paint finish. a) Main Entrance 8 Sq.m 10. STORAGE UNIT : Providing and placing in position Storage units fabricated out of 19mm thick BWP block board on all sides, backing and separators will be of 6mm thick BWP ply, shelves and shutters will be of 19mm thick BWP solid ply. The top, sides, shutter front and back sides (if exposed) to be finished with 1mm thick laminate with necessary grooves and the exposed edges of block board should be finished with 6mm t.w. lipping. Inside of the unit will be polished in matching tone. Unit should be provided with locks, hinges, sliding drawer channels, handles, ball catchers and tower bolt fixed. There should also be a 75 x 12 mm t.w. skirting with grooves as per design polished in matching tone. 15 Sq.m 11/20/2009 boq7 Anil Associates Architects Tel; 9810007032 Sl. No. Description of Item Qty. Unit Rate (Rs.) I fig. Rate (Rs.) in words Amount (Rs.) BILL OF QUANTITY FOR INTERIOR WORK INCLUDING FURNISHING, ELECTRICAL & CIVIL WORK OF PUNJAB AND SIND BANK , SANTPURA TILAK NAGAR NEW DELHI BRANCH . 11. SIDE & BACK UNIT: Providing and placing in position side and back units fabricated out of 19mm thick BWP block board on all sides, backing and separators will be of 6mm thick BWP ply, shelves and shutters will be of 19mm thick BWP solid ply. The top, sides, shutter front and back sides (if exposed) to be finished with 1mm thick laminate with necessary grooves and the exposed edges of block board should be finished with 6mm t.w. lipping. Inside of the unit will be polished in matching tone. Unit should be provided with locks, hinges, sliding drawer channels, handles, ball catchers and tower bolt fixed. There should also be a 75 x 12 mm t.w. skirting with grooves as per design polished in matching tone. (Only front area to be measured for payment.) 8 Sq.m 11/20/2009 boq8 Anil Associates Architects Tel; 9810007032 Sl. No. Description of Item Qty. Unit Rate (Rs.) I fig. Rate (Rs.) in words Amount (Rs.) BILL OF QUANTITY FOR INTERIOR WORK INCLUDING FURNISHING, ELECTRICAL & CIVIL WORK OF PUNJAB AND SIND BANK , SANTPURA TILAK NAGAR NEW DELHI BRANCH . 12. TABLE : Providing and placing in position table fabricated out of 19mm thick BWP block board on all sides finished with 1.5 mm thick laminate on top, 1mm thick laminate on the sides and front. Exposed surfaces are to be finished with 1mm thick laminate. Table edges are to be finished with t.w. moulding duly polished. There should be a 75 x 12 mm skirting with grooves duly melamine polished. Exposed edges of the boards will be finished with t.w. lipping. a) Running Table for Cash.( 750 mm depth) 3 RM b) Clerk's Table (1200 x 750mm )- table top. 7 Nos. c) Running table (600 depth) 3 RM d) Help Desk 1 Nos. e) Manager Table for Cash.( 2000x 750 mm depth) 1 Nos. f) OfficerTable .( 1800x 750 mm depth) 2 Nos. 11/20/2009 boq9 Anil Associates Architects Tel; 9810007032 Sl. No. Description of Item Qty. Unit Rate (Rs.) I fig. Rate (Rs.) in words Amount (Rs.) BILL OF QUANTITY FOR INTERIOR WORK INCLUDING FURNISHING, ELECTRICAL & CIVIL WORK OF PUNJAB AND SIND BANK , SANTPURA TILAK NAGAR NEW DELHI BRANCH . 13. VERTICAL BLIND – Providing and fixing vertical blinds having 25mm high grade aluminium alloy slats with 0.19mm thickness and 100mm wide. The head channel should be of GI steel U shaped PU powder coated fitted with guardian tilter having Tomised steel housing and self lubricating nylon automatic disengaging worm and gear mechanism, all the fixtures in the top rail including Drums, Cradle, Tilt rod, etc will be of Tomised steel with 19mm bottom rail made of GI steel in matching colour. The slat is to be placed on braided polyester yarn. The top rail is to be fixed on GI steel “L” shaped swivel bracket to hold head channel. The blind will be in approved colour shade. (Payment will be made on the basis of brickwork opening) ( Make : Classic, Veesta or equivalent ) 16 Sq.m 14. PIN-UP BOARDS : Supplying and fixing pin-up boards fabricated out of 12mm BWP ply covered with 12mm soft board padding and upholstered with poly propylene fabric @ Rs. 150/- per meter edges of soft board should have t.w. moulding duly spirit polished. 8 Sq.m 11/20/2009 boq10 Anil Associates Architects Tel; 9810007032 Sl. No. Description of Item Qty. Unit Rate (Rs.) I fig. Rate (Rs.) in words Amount (Rs.) BILL OF QUANTITY FOR INTERIOR WORK INCLUDING FURNISHING, ELECTRICAL & CIVIL WORK OF PUNJAB AND SIND BANK , SANTPURA TILAK NAGAR NEW DELHI BRANCH . 15. PLANTERS : Providing and placing planters ( 450 x 450 x 450 ) of appropriate size made out of 19 mm block board & outer side finished with 1mm laminate of appropriate shade & colour in position of plants. 6 Nos. 16. PAINTING : Providing and applying 2 coats of plastic emulsion paint over 1 coat of primer of approved shade and colour on walls, columns and ceiling. The job is inclusive of scraping, leveling and preparing the surface, applying primer, etc. 130 Sq.m 17. ENAMEL PAINING : Providing and applying 2 coats of enamel paint over 1 coat of primer of approved shade as per direction of the Architect. The job is inclusive of scraping, leveling and preparing the surface, applying primer, etc. 30 Sq.m 18. GRANITE LEDGE: Providing and placing in position 19mm thick Black Galaxy Granite counter top at cash counter and case team counters with machine polished and moulded edges fixed in position with mouldings, etc., as per design 7 Sq.m 11/20/2009 boq11 Anil Associates Architects Tel; 9810007032 Sl. No. Description of Item Qty. Unit Rate (Rs.) I fig. Rate (Rs.) in words Amount (Rs.) BILL OF QUANTITY FOR INTERIOR WORK INCLUDING FURNISHING, ELECTRICAL & CIVIL WORK OF PUNJAB AND SIND BANK , SANTPURA TILAK NAGAR NEW DELHI BRANCH . 19. WIRE MANAGERS : Providing and fixing in position PVC 75mm dia Wire Managers of approved make. 10 Nos. TOTAL QUOTED AMOUNT FOR SUPPLY OF FURNISHING WORKS IN RS. TOTAL Section B : Electrical Work. 1 Providing and fixing of panel board of 18 SWG mild steel properly painted with main switch TPN 100Amps with HRC fuse make Havel and busbar with copper strip TPN with size 25x4x300mm mounted on porcelain base and 3 each indicators and light phase changer 63Amps.2 pol. And volt meterwith panel connected to main(panel with double door. 1 Each 2 Providing and fixing with distribution box main isolator DP 63 Amps, MCB and UPS outgoing 32 Amps. DP MCB in common MCB 12 way DB of 6Amps. MCB with 2x4sqmm and 1x1.5sqmm. PVC insulated copper wire through PVC conduit from UPS make 11/20/2009 boq12 Anil Associates Architects Tel; 9810007032 Sl. No. Description of Item Qty. Unit Rate (Rs.) I fig. Rate (Rs.) in words Amount (Rs.) BILL OF QUANTITY FOR INTERIOR WORK INCLUDING FURNISHING, ELECTRICAL & CIVIL WORK OF PUNJAB AND SIND BANK , SANTPURA TILAK NAGAR NEW DELHI BRANCH . MDS(6Amp MCB Qty-B) 1 Each 3 Providing and laying main circuit wiring with 2x6 sqmm. And 1x1.5sqmm. PVC insulated copper conductor through PVC conduit from main lineto UPS distribution box connected Item no. 2. 145 Rmt 4 Providing and computor circuit wiring 2x1.5sqmm. and 1x1 sqmm. PVC insulated copper wire through PVC conduit pipe connected UPS distribution box to computer switch board. 20 Each 5 Providing and fixing switch board with in each board Qty. 3 switch, 3 socket and one indicator to wooden box and sunmica sheet connected by for UPS. 15 Each 6 Providing and laying power point for air-conditioning with industrial type socket and MCB 32 Amps.with M.S. boxes with 2x4 sqmm. And 1.1 sqmm. PVC copper wire through PVC conduit pipe. 8 Each 7 Providing and laying telephone wiring and TP jack with boxes wire through PVC pipe all as directed by Bank. 4 each 11/20/2009 boq13 Anil Associates Architects Tel; 9810007032 Sl. No. Description of Item Qty. Unit Rate (Rs.) I fig. Rate (Rs.) in words Amount (Rs.) BILL OF QUANTITY FOR INTERIOR WORK INCLUDING FURNISHING, ELECTRICAL & CIVIL WORK OF PUNJAB AND SIND BANK , SANTPURA TILAK NAGAR NEW DELHI BRANCH . 8 Providing and fixing speaker wiring and speaker point through out PVC pipe from music system. With speaker 4 Each 9 Supply Fixing single tubelight fitting including loop wire through PVC conduit to false ceiling/ direct to roof. 6 Each 10 Supply, Fixing mirror optics double tubelight fitting with loop wiring2x1.5sqmm. And 1x1 sqmm.wire through PVC pipe all as directed by bank. (Phillipsor crompton Make size 2" x 2" with four no lamps) 20 EACH 11 Supply fixing wall fancy light fittings to loop wiring 2x1.5 sqmm. and 1x1 sqmm.PVC insulated copper. wire throufh PVC conduit pipe. 12 EACH 12 Providing and fixing points in toilets for exhaust fan with wire 2x1.5 sqmm. And 1x1sqmm. Wire through PVC conduit pipe. 2 EACH 11/20/2009 boq14 Anil Associates Architects Tel; 9810007032 Sl. No. Description of Item Qty. Unit Rate (Rs.) I fig. Rate (Rs.) in words Amount (Rs.) BILL OF QUANTITY FOR INTERIOR WORK INCLUDING FURNISHING, ELECTRICAL & CIVIL WORK OF PUNJAB AND SIND BANK , SANTPURA TILAK NAGAR NEW DELHI BRANCH . 13 Providing and laying light points with wiring 2x1.5sqmm. And 1x1 sqmm. Wire PVC insulated copper wire through PVC conduit pipe. 15 EACH 14 Supplying and Fixing ceiling/ Wall fans and wall fan with loop wiring 2x1.5sqmm. And 1x1sqmm. Wire PVC conduit pipe. 12 EACH 15 Providing and fixing power point wiring in insulated 2x6sqmm. And 1x1sqmm. PVCinsulated copper wire through PVC conduit pipe and switch and socket with saddles etc. complete. 10 EACH 16 Providing and testing on earth station as per IS 3042 of 1996 with copper ground plate electrode (600x600x3mm) at a proper depth. The rate should be inclusive of constructing inspection chamber 32mm dia watering G.I. Pipe with reducer. C.I. Cover and fittings of required quantity of salt and charcoal etc. as directed by the bank and as per drawing attached. 2 EACH 11/20/2009 boq15 Anil Associates Architects Tel; 9810007032 Sl. No. Description of Item Qty. Unit Rate (Rs.) I fig. Rate (Rs.) in words Amount (Rs.) BILL OF QUANTITY FOR INTERIOR WORK INCLUDING FURNISHING, ELECTRICAL & CIVIL WORK OF PUNJAB AND SIND BANK , SANTPURA TILAK NAGAR NEW DELHI BRANCH . 17 Supply line and connecting 4mm dia copper earth conductor with nut bolts washers etc.complete all as directed by the bank including 12.5mm dia G.I. pipe frame pit to wall upto 6'-0" height and 12.5mm IS mark PVC pipe up to UPS for protection of earth wire. 45 RMT. 18 Providing and making of the electrical points taking extension points all complate with switch,sockets ,wires, PVC beading on surface/ partions, etc all complet as per the direction and requirments of the Bank . 15 A 5 Nos 5Amp 8 Nos. TOTAL QUOTED AMOUNT FOR ELECTRICAL WORKS IN RS. PART C CIVIL WORKS 1 Providing and laying VETRIFIED TILE skirting / risers of approved shade and make in CM 1:4 in proper line and level. The skirting should be flushed with the level of P. O. P. Punning on wall with 1/4" grove. Rate shall be inclusive of providing and laying 95.00 Smt 11/20/2009 boq16 Anil Associates Architects Tel; 9810007032 Sl. No. Description of Item Qty. Unit Rate (Rs.) I fig. Rate (Rs.) in words Amount (Rs.) BILL OF QUANTITY FOR INTERIOR WORK INCLUDING FURNISHING, ELECTRICAL & CIVIL WORK OF PUNJAB AND SIND BANK , SANTPURA TILAK NAGAR NEW DELHI BRANCH . 2 Construction of the ATM Room made out of 9" thick brick wall with cement plaster on both the side with the nacessary modification in the rolling shutter etc all complete , as required by the new layout plan and stacking the as directed by the Bank . 1.00 Job TOTAL QUOTED AMOUNT FOR CIVIL WORKS IN RS. 11/20/2009 boq17 Anil Associates Architects Tel; 9810007032 Sl. No. Description of Item Qty. Unit Rate (Rs.) I fig. Rate (Rs.) in words Amount (Rs.) BILL OF QUANTITY FOR INTERIOR WORK INCLUDING FURNISHING, ELECTRICAL & CIVIL WORK OF PUNJAB AND SIND BANK , SANTPURA TILAK NAGAR NEW DELHI BRANCH . Section A : Furnishing Work. Rs. Section B : Electrical Fittings. Rs. Section C : Civil Works. Rs. TOTAL Rs. ABSTRACT OF ESTIMATES 11/20/2009 Bid Document : Document Not available Tech. Document : Document Not available Sector : Finance & Revenue State : Delhi For further Information Contact: Name : As per Contact Address | 
